Universiti Teknologi Malaysia Institutional Repository

Kelewatan projek pembinaan sektor awam negeri Perak

Haron, Jafni (2020) Kelewatan projek pembinaan sektor awam negeri Perak. Masters thesis, Universiti Teknologi Malaysia, Faculty of Engineering - School of Civil Engineering.

[img] PDF

Official URL: http://dms.library.utm.my:8080/vital/access/manage...


Delay in a construction project can be defined as the late completion of works as compared to the contract schedule or planned schedule. Construction projects can be delayed due to so many factors. It may be due to consultant, contractor, and client itself. The aim of this study is to investigate factors that causes delay and the effects of construction project delay on Perak Public Sector and finally to identify the relevant ways of eliminating or mitigating these construction delays. The combination of literature review, short survey, document analysis and opinions from the practitioners reveals that causes of delay are attributed by eight (8) categories comprises contractor, client, material, labour, equipment, financial and external causes. The analysis shows that the severe impact of the delay as perceived by respondents is increased in cost due to imposition of LAD, loss expenses, additional insurance coverage and the possibility of legal proceeds due to arbitration or litigation. Determines the appropriate level of funding at the planning stage so that fixed payments must be paid to the contractor and comprehensive analysis of construction period at the planning stage are suggested as ways of overcoming and minimising delay on public sector construction projects in Perak.

Item Type:Thesis (Masters)
Additional Information:Thesis (Sarjana Kejuruteraan (Pengurusan Pembinaan)) - Universiti Teknologi Malaysia, 2020; Supervisor : Assoc. Prof. Dr. Aminah Md Yusof
Subjects:T Technology > TA Engineering (General). Civil engineering (General)
Divisions:Civil Engineering
ID Code:85870
Deposited By: Fazli Masari
Deposited On:30 Jul 2020 15:38
Last Modified:30 Jul 2020 15:38

Repository Staff Only: item control page